Cases Decided in the United States Court of Claims ... with Report of Decisions of the Supreme Court in Court of Claims Cases, 123. sējumsThe Court, 1958 |
No grāmatas satura
1.–5. rezultāts no 99.
5. lappuse
... plaintiff is con- cerned with delay in commencing plastering work due to inability to secure rock lath for the 2 - inch partitions speci- fied in the contract ( sometimes referred to as gypsum board or wallboard ) . Plaintiff's letter ...
... plaintiff is con- cerned with delay in commencing plastering work due to inability to secure rock lath for the 2 - inch partitions speci- fied in the contract ( sometimes referred to as gypsum board or wallboard ) . Plaintiff's letter ...
8. lappuse
... plaintiff's letter of that date ( which letter has not been relied on by plaintiff in this proceeding ) in which plaintiff states that the delay will cost plaintiff considerable money but that plaintiff is not requesting additional ...
... plaintiff's letter of that date ( which letter has not been relied on by plaintiff in this proceeding ) in which plaintiff states that the delay will cost plaintiff considerable money but that plaintiff is not requesting additional ...
9. lappuse
... plaintiff was seeking extra - legal relief from losses . Plaintiff's only mention of possible loss is in the letter of July 25 in which it refers to the possibility of addi- tional costs in the future . Plaintiff also relies on a letter ...
... plaintiff was seeking extra - legal relief from losses . Plaintiff's only mention of possible loss is in the letter of July 25 in which it refers to the possibility of addi- tional costs in the future . Plaintiff also relies on a letter ...
49. lappuse
... plaintiff claims damages for breach of the contract due to delays resulting in extra costs to plaintiff and where plaintiff's claim is based on four causes of action ; it is held that plaintiff is entitled to recover on the third and ...
... plaintiff claims damages for breach of the contract due to delays resulting in extra costs to plaintiff and where plaintiff's claim is based on four causes of action ; it is held that plaintiff is entitled to recover on the third and ...
50. lappuse
... plaintiff was in no way responsible for the delay nor was the grading contractor . Plaintiff is entitled to recover . United States 74 Same ; rental value of equipment . - The fair rental value of equipment rendered idle by delays ...
... plaintiff was in no way responsible for the delay nor was the grading contractor . Plaintiff is entitled to recover . United States 74 Same ; rental value of equipment . - The fair rental value of equipment rendered idle by delays ...
Citi izdevumi - Skatīt visu
Bieži izmantoti vārdi un frāzes
active duty agreement alleged amended amount appeal April April 16 Army August August 14 authorized award Board cause of action charges Chief Colo Company compensation Congress construction contracting officer contractor Corporation cost counterclaim Court of Claims damages December decision defendant defendant's motion denied dredging employees engine entitled to recover February Fedala filed Findings of Fact follows Fort Collins grade Holmes Baldridge ignition system issued January Judge July July 15 June 24 labor letter Longmont magneto March material ment motion for summary Naval Navy November October October 19 October 27 oysters paid patent payment period plaintiff plaintiff is entitled plaintiff's claim Plaintiff's motion Plaintiff's petition potatoes prior received referred Regional Office request retired pay Secretary Section Sedgwick County September September 13 shielding spark plug specifications Stat statute suit summary judgment supra terminal tiff tion Union United War Assets Administration
Populāri fragmenti
511. lappuse - Gross income" includes gains, profits, and income derived from salaries, wages, or compensation for personal service, of whatever kind and in whatever form paid, or from professions, vocations, trades, businesses, commerce, or sales, or dealings in property, whether real or personal, growing out of the ownership or use of or interest in such property; also from interest, rent, dividends, securities, or the transaction of any business carried on for gain or profit, or gains or profits and income derived...
63. lappuse - Officer grants a further period of time before the date of final payment under the contract), notifies the ContractIng Officer In writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, In his Judgment, the findings of fact justify such an extension, and his findings of fact shall be final and conclusive on the parties subject only to appeal as provided in the clause of this contract entitled "Disputes.
478. lappuse - All claims and demands whatever by the Government of the United States or against it, and all accounts whatever in which the Government of the United States is concerned, either as debtor or creditor, shall be settled and adjusted in the General Accounting Office.
62. lappuse - ... unforeseeable causes beyond the control and without the fault or negligence of the contractor, including, but not restricted to, acts of God, or of the public enemy, acts of the Government, acts of another contractor in the performance of a contract with the Government, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather or delays of subcontractors due to such causes...
106. lappuse - ... the contracting officer in writing of the causes of delay. The contracting officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when in his judgment the findings of fact justify such an extension, and his findings of fact thereon shall be final and conclusive on the parties hereto, subject only to appeal by the contractor to the Commission in accordance with Article hereof entitled "Disputes.
818. lappuse - Disputes. — Except as otherwise specifically provided in this contract, all disputes concerning questions of fact arising under this contract shall be decided by the contracting officer subject to written appeal by the contractor within 30 days to the head of the department concerned or his duly authorized representative, whose decision shall be final and conclusive upon the parties thereto. In the meantime the contractor shall diligently proceed with the work as directed.
513. lappuse - Here we have the essential matter: Not a gain accruing to capital, not a growth or increment of value in the investment, but a gain, a profit, something of exchangeable value proceeding from the property, severed from the capital however invested or employed, and coming in, being "derived...
44. lappuse - labor dispute" includes any controversy concerning terms or conditions of employment, or concerning the association or representation of persons in negotiating, fixing, maintaining, changing, or seeking to arrange terms or conditions of employment, regardless of whether or not the disputants stand in the proximate relation of employer and employee.
107. lappuse - Act of 1949 in the construction or development of the project, will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account (except such payroll deductions as are permitted by...
202. lappuse - ... the Government may, by written notice to the contractor, terminate his right to proceed with the work or such part of the work as to which there has been a failure to pay said required wages and to prosecute the work to completion by contract or otherwise, and the contractor and his sureties shall be liable to the Government for any excess costs occasioned the Government thereby.